A structure for the purpose and function of habitation and other uses.

Physical planning at site, community or urban level by an Architect.

A person professionally and academically qualified, registered and licensed under

R.A.9266 with the certificate of registration and professional identification card issued by the Professional Board of Architecture and the Profession Regulation Commission and

who is responsible for the advocating the fair and sustainable development, welfare and

cultural expression of society’s habitat in terms of space, forms and historical context.

A group of professionals in architecture and allied profession, incorporated with architects for the purpose of delivering professional service in architecture and allied professionals.

A registered and licensed architect, who is academically and professionally qualified and with exceptional or recognized expertise or specialization in any branch of architecture.

An architect who is not a Filipino citizen nor an architect registered and licensed in the Philippines, but who is duly registered and licensed in his/her home country as an architect.

Physical and systematic design undertaken by the architect on a community and urban plane, more comprehensive than, and an extension of the architecture of buildings, spaces between buildings, entourage, utilities and movement systems.

An individual architect practicing and delivering architectural services, duly registered with  DTI, BOA, and the PRC.

A person whose name and registration/professional license number is entered in the PRC registry book and computerized data base as one legally to practice his profession.

The architect who design  and  advocated  the Geodesic Dome for the cities of tomorrow was.

Through the history of human race, what is considered the mother of all arts.

In Egyptian architecture, the tomb of Pharaoh was the

The mineral of greatest importance to Greek architecture of which Greece and her   domains had ample supplies of was

Greek architecture was essentially

Forming the imposing entrance to the acropolis and erected by architect Minescicles is the

Which of the orders was added by the Romans to the orders used by the Greeks.

The finest example and remaining example of Byzantine Architecture is

The greatest patron of Romanesque architecture is the

An ornate architectural style which developed during the latter part renaissance period is called

Monumental gateway of Egyptian temple is

The monumental architecture of Egypt is essentially

The most important and distinctive characteristics or nature of Spanish Romanesque architecture was the

The architectural character of Romanesque style is

In the early years of city planning, who advocated the principles of neighborhood planning.

The law to enhance the mobility of disabled person is also known as;

Under PD1096, parking areas for disabled person shall be how many meters from the facility being served.

Under accessibility law, walk way should have a gradient of not more than

Accessible parking slots should have a min width of

The min. width of ramp for disabled person should be

The maximum gradient of ramp shall be

The min.  width of door for disabled person shall be

The accessible water closet stall  shall have a min. area of

The required turning space for accessible water closet shall be

The min. width of curb cut-out  for disabled person shall be

A professional services in which the architect act as the agent of the client.

UAP Doc 202 is also known as

If the project abandoned or suspended, in whole or in part of,  the Architect is to be paid by the owner for the services rendered equivalent to how many percent oh his MBF.

Under Post Construction Services, Bldg. and equipment maintenance is also known as

Under construction services, the compensation of the architect as a full time supervisor shall be

Instructions that supplement or modify drawings, specs, & general conditions of the contract.

Addt’l info issued as an addition or amendment to provisions of specs.

Info, advice or notification pertinent to the project

Additional information on contract documents

Shall mean “purchase and/or fabricate and deliver to the jobsite”

Shall mean, build in, mount in positions, connect or apply

Approved form of security furnished by the contractor as a guarantee to execute work in accordance with terms of the contract.

Approved form of security furnished by the contractor as guarantee to pay all obligations arising from the contract

Approved form of security furnished by the contractor to guarantee to the quality of materials and workmanship performed.

Owner shall furnish contractor ______of drawings and specs for free.

Contractor shall prepare at his own expense and submit _______ of all shop drawings to the architect, who will make the necessary corrections, and file the corrected copies.

Drawings shall be accompanied by a letter of transmittal _________ containing name of project, contractor, number of drawings, titles and other pertinent data.

_________will secure the occupancy permit.

________is responsible for establishment of boundaries made by a licensed surveyor.  

Contractor shall furnish ________ of complete catalogue data for every item of equipment.

A room of approx. ____ shall be provided for the use of the architect as office.

Plants needed to be transplanted within _________ must be done at the expense of the contractor.

The supervisor must be a licensed engineer or architect who will work personally and inspect at least

Stakes, benchmarks placed by contractor shall be gradually preserved and maintained by the __________.

 If such are displaced or damage due to neglect, it must be replace them at his own expense.

The architect may examine work already completed before final acceptance. If work is found defective due to contractor’s fault, he shall defray all the expenses of such examination and satisfactory reconstruction. If work is found to be satisfactory, actual cost of labor and materials in examination plus ____ shall be allowed the contractor and granted extension time on account of additional work.

Adjustment of drawings to suit field conditions may be necessary during construction. The contract recognizes the essence of this as long as resulting overruns and underruns do not exceed _____ Discrepancies shall be submitted immediately to the architect before adjustments

Value of extra work shall be determined by unit prices stipulated in contract provided that the extra does not exceed _____ of the original contract details.or Actual direct cost plus 15% for contractor’s profit, overhead and contractor’s tax.

Claim of adjustment must be asserted within ________ from date of the order of change unless architect will extend the time.

If any instructions in drawings involve extra cost, the contractor will inform the architect through written notice within _______ after the receipt of such instruction

If delays incur in mobilization of work, the contractor must give the architect a written notice within ________ after recognition of delay and proceed to claim the extra cost.

The contractor shall execute at his own expense all work necessary for making good of known defects within the period of _______ after the issuance of the certificate of completion

Contractor will be allowed an extension based on the delay due to the employees of the owner and the owner himself, act of god or force majeure, delay by the architect pending arbitration, the contractor shall within ______ from the occurrence of such delay file the necessary request of extension for the approval of the architect.

Contractor shall submit written notice to the architect at least 10 days prior to beginning, suspending or resuming the work to the end that the architect may make preparations for inspection without delaying the work. All delays resulting from failure of the contractor are the contractor’s risk. All extra costs due to such delay will be deducted from the final payment.

The contractor shall, within 15 days from receipt of notice to proceed, submit a complete breakdown of work and corresponding value for approval and will be used as basis for all requests for payment.

Contractor shall complete all the work contracted in the time stated. Computation of the contract time shall commence on the ______ from receipt of the notice to proceed.

The contractor shall submit a request for payment for work done, not more than once each month. Each request shall be computed from the work completed on all items listed in the breakdown of work, less 10% retention.

When _____ of the contract has been accomplished, no retention shall be made.

Photograph size shall be ______. Four exposures shall be taken (2 copies for each exposure = 8), a total of 8 prints to be delivered to the architect, and all negatives bearing the date of exposure and name of work

______ upon receipt of the request for payment, the architect shall either issue a certificate of payment or withhold the request and inform the contractor in writing the reasons for withholding it. The certificate of payment shall include the value of work accomplished during the period of time covered by the certificate

Within ______ from the date of approval of a request for payment and issuance of certificate of payment, the owner shall pay the amount as certified, or such other amount he deems is due the contractor informing both the contractor and architect in writing his reasons for paying the amended amount.

No payments shall be made in excess of _______ of the contract price unless a notarized statement is submitted by the contractor to the effect that all bills for labor, other than current wages, and bills for materials have been paid.

Guarantee bond equivalent to ______ of the contract price covering a period of 1 year after the final acceptance of the work shall be issued by the contractor

The amount retained by the owner shall be released ______s after the date of the final payment.

The contractor may suspend or terminate work upon ______ written notice to the owner and architect for the following:

Order of court or public authority caused the work to stop or suspension for 90 days through no act of the contractor and employees.

If architect fails to act upon request for payment within 15 days after presented.

If owner fails to act upon request for payment within 15 days after presented.

If owner fails to pay the contractor within 30 days after its award by arbitration.

A small elevator used to convey food or other goods from one floor of a building to another floor.